Award by an Arbitral Tribunal (India)
This template provides a structured format for a presiding arbitrator to issue a final decision (award) following an arbitration process. It outlines findings regarding construction delays, defects, and financial compensation between a contractor and a property owner.
Award by an Arbitral Tribunal
This is the Award by the undersigned, made the ………..day of ………
Whereas by an agreement under the deed, dated………..and made between (contractor) of the one part and…………….(owner of the property)of the other part (being an agreement by the said contractor) to construct certain works upon the land of the said (owner) in accordance with sanctioned plans and specifications contained therein it was agreed between the parties that if any dispute should arise in future between the parties thereto relating to or touching the said agreement or the interpretation thereof or in relation to the rights, duties or liabilities of either party thereunder the same should be referred to two arbitrators and their umpire in accordance with the provisions of Arbitration & Conciliation Act, 1996.
and Whereas disputes having arisen between the aforesaid parties relating to the said agreement the said (contractor) by writing dated……….nominated and appointed Shri…………(one arbitrator)…………of etc, and the said (owner) by writing dated……………..nominated and appointed Shri………..(other arbitrator)…….of etc, to act as arbitrators and settle the said matters in dispute between the parties.
and Whereas the said arbitrators respectively accepted the said appointments and took upon themselves to discharge the burden of the said reference and before starting the proceeding for the consideration of the disputed matter referred to them by writing under their hands dated……….appointed me the said Presiding Arbitrator in the said arbitration.
and Whereas the said arbitrators duly extended the time for making the award until the ………..day of………….
and Whereas the said arbitrators were unable to agree amongst themselves unanimously upon an award and under such circumstances gave me notice in writing dated………….and thereupon the disputes stood referred to me.
Now be it Know that, I, said Presiding Arbitrator, make my award on the following matter:
1. I find that the completion of the work although was delayed for……..months beyond the agreed date on which it ought to have been completed but I find that such delay was caused partly by exceptionally bad weather and partly by lack of workmen caused by labour strikes and also their having taken up construction works under the Government and I find and award that the said (contractor) is not liable for any damage on that account.
2. I find that a part of the work executed by the said(contractor) was found to be defective in the following respects…………..(defects set out) and I award that the said (owner) is entitled to Rs………….as damages on that account.
3. I find and award that after deducting the said sum of Rs……on account of the damages there is still due and owing to the said (contractor) in respect of the matters in dispute between the said parties to reference the sum of…………..
4. I direct the said (owner) shall pay the said sum of Rs………..to the said (contractor) on or before the ………..day of……..
5. I award and direct that the cost of the said (contractor) relating to and incidental to this arbitration reference including the costs of the arbitrators and of this award which is Rs………..shall be borne and paid by the said (owner) or whatever may be the award as to costs.
……………………..…(Sd.)
5.0 out of 5 on Google
Read reviewsAs seen in
Frequently asked questions
A template isn't binding on its own - like any contract, it becomes binding once it's properly completed and signed. Templates in our curated library are professionally drafted for US or UK law; review any template before you sign it.
Yes. Chat with GitLaw to edit any section, or make changes directly in the editor.
Yes, read about team plans here.
Describe what you need in the chat and GitLaw will draft it for you.
Templates in our curated library are professionally drafted for US or UK law. The wider library comes from the GitLaw community and public sources - a solid starting point, but check any template fits your situation before you rely on it.
Mostly US and UK law. Some templates use general commercial terms that work across jurisdictions, and many note which law they're written for.
It depends on the situation. Templates work well for routine business agreements. For anything involving significant money, complex IP, employment, or areas you're unsure about, it's worth getting professional advice before you sign. GitLaw provides templates and tools, not legal advice.
Open any template in GitLaw and describe the change you want in the chat — 'make clause 4 mutual' or 'add a 30-day notice period', for example. GitLaw drafts the revised language and shows it as a suggested edit. You accept, reject, or keep editing from there.
Yes. Upload a Word, PDF, or Markdown file and GitLaw will open it in the editor. You can review, edit, or chat with GitLaw about it the same way you would with any template from the library.
Trusted by thousands of businesses
From template to signed, in one place
Every template opens in an editor with an AI agent alongside it.
Open
Pick a template and open it. Nothing to download, and no credit card to start.
Free to open
Edit with AI
Describe your situation in chat and the agent adapts the wording, clause by clause.
Tracked changes you can review
Send and sign
Share it for negotiation, then collect signatures without leaving GitLaw.
eSign included
Built for your legal work, with practicing lawyers
Trained on 5.5K+ clauses and specialist areas of law. Built with a standards committee of independent lawyers.
As seen in
Start free
No sales calls, no credit card. Just chat with GitLaw.
GitLaw provides templates and tools, not legal advice. Templates are a starting point, not a substitute for advice on your situation - for anything significant, speak to a qualified lawyer.