Notice under Section 11 of the Arbitration and Conciliation Act, 1996 (India)
This document is a formal notice used to initiate the appointment of an arbitrator under Section 11 of the Indian Arbitration and Conciliation Act. It is typically used when a construction project has been delayed or defectively performed, and the parties need to resolve their dispute through a pre-agreed arbitration process.
NOTICE UNDER SECTION 11 OF ARBITRATION AND CONCILIATION ACT 1996
Date………
To
M/s.......................................Address………………………….
Arbitration of controversies emerging under Contract No. 3 entered with us.
Dear Sirs,
You have entered Contract No……. with us undertaking to build office complex as per terms/conditions existing in said contract.
You have not constructed building along with delivery of possession, which you had consented to build on our behalf.
You have been paid advances and all your running bills by us, despite this; you are delaying the matter inordinately. Time being essence of the contract, you have not followed the time schedule.
Some part of building you have built and consented for joint inspections were seen has defective and unsuitable for occupation.
Despite requests you have neglected in completing the work. Due to contravention of this agreement we have suffered losses and these losses are continuing suffering each day. Our huge investment stands blocked. We have to pay interest to our Banker for the finance got in making payment to you.
As Per clause No….. of said contract, there exist an agreement for referring the controversies by Arbitration to Mr. …………………………………………….., Advocate of …………………………………………………
Per enactments of section 11 of Arbitration and Conciliation Act 1996 we hereby serve you notice for approving the selection of Mr. ……………………………………………………………., Advocate, being Sole Arbitrator in the matter of differences and controversies which have emerge between the parties herein and the same be referred for adjudication to him.
The said controversies are, inter alias, the following:
(a) If the construction of Office complex per said Contract No……………….……. being according to the contract?
(b) If the Building has been completed according to specification with terms/conditions of the contract?
(c) If the contractor has handed over completed building
(d) If we has sustained any loss/damages owing to breach of the terms/conditions of the contract by you?
(e) What is the damage with indemnification which the employer bear right to get from the contractor?
Please give your concurrence within ..days of receipt of this letter.
Yours faithfully
Signature
5.0 out of 5 on Google
Read reviewsAs seen in
Frequently asked questions
A template isn't binding on its own - like any contract, it becomes binding once it's properly completed and signed. Templates in our curated library are professionally drafted for US or UK law; review any template before you sign it.
Yes. Chat with GitLaw to edit any section, or make changes directly in the editor.
Yes, read about team plans here.
Describe what you need in the chat and GitLaw will draft it for you.
Templates in our curated library are professionally drafted for US or UK law. The wider library comes from the GitLaw community and public sources - a solid starting point, but check any template fits your situation before you rely on it.
Mostly US and UK law. Some templates use general commercial terms that work across jurisdictions, and many note which law they're written for.
It depends on the situation. Templates work well for routine business agreements. For anything involving significant money, complex IP, employment, or areas you're unsure about, it's worth getting professional advice before you sign. GitLaw provides templates and tools, not legal advice.
Open any template in GitLaw and describe the change you want in the chat — 'make clause 4 mutual' or 'add a 30-day notice period', for example. GitLaw drafts the revised language and shows it as a suggested edit. You accept, reject, or keep editing from there.
Yes. Upload a Word, PDF, or Markdown file and GitLaw will open it in the editor. You can review, edit, or chat with GitLaw about it the same way you would with any template from the library.
Trusted by 5,000+ businesses
From template to signed, in one place
Every template opens in an editor with an AI agent alongside it.
Open
Pick a template and open it. Nothing to download, and no credit card to start.
Free to open
Edit with AI
Describe your situation in chat and the agent adapts the wording, clause by clause.
Tracked changes you can review
Send and sign
Share it for negotiation, then collect signatures without leaving GitLaw.
eSign included
Built for your legal work,
with practicing lawyers
Trained on 5,500+ clauses and specialist areas of law. Built with a standards committee of independent lawyers.
As seen in
Ready to get started?
No sales calls, no credit card. Just chat with GitLaw.
GitLaw provides templates and tools, not legal advice. Templates are a starting point, not a substitute for advice on your situation - for anything significant, speak to a qualified lawyer.