Free Construction & Engineering Contracts Templates

A building construction contract on a fee-plus-cost basis, under which a contractor constructs a house on the owner's plot according to an architect's sanctioned plans in India, being reimbursed the cost of labour and materials plus a fee. It covers the standard and manner of construction to the architect's satisfaction, commencement and completion with liquidated damages for delay (capped at 2%), stage-wise payments certified by the architect with 5% retention money and a 12-month defects-liability period, free access to site, the contractor's indemnity for injury and damage, the owner's extensive rights on the contractor's default or abandonment (termination, taking over materials and plant, and completion by others, with the architect's final certification of accounts), appointment of a site engineer, inspection and rectification of defects, and dispute resolution by arbitration.

An agreement for the transfer of development rights over a plot in India, under which landowners (Vendors), with their existing developer (Confirming Party) joining, grant a third builder (Purchasers) the right to construct a specified building on a sub-divided sector plot and to sell the flats therein on ownership basis. It covers the consideration per square foot of built-up area and the payment schedule, permitted amendments to sanctioned plans, the purchasers' right to sell units in their own name and retain the proceeds, rights of way and shared use and maintenance of internal roads and services, apportionment of taxes and outgoings, handover of possession with authority to construct and advertise, formation of the flat purchasers' society and eventual conveyance or 99-year lease, indemnities, the completion timeline, and required tax clearances and permissions.

This template is a formal **Power of Attorney** designed for use in India, allowing a property owner to authorize a developer to manage building projects. It grants the developer the power to obtain government approvals, negotiate with tenants, manage construction, and sell specific units once completed.

This template provides a comprehensive **Power of Attorney** for Indian property owners to grant developers the legal authority to manage land development. It allows the appointed attorneys to handle municipal permits, deal with government authorities, and execute the final deed of conveyance to transfer ownership to the developer or a housing society.

This template provides an **Irrevocable Power of Attorney** for landowners to grant extensive rights to developers following a sale agreement. It allows developers to handle all administrative, legal, and construction-related tasks, including obtaining municipal sanctions, selling residential units, and executing final conveyances.

A turnkey building construction agreement between an owner (the Employer) and a contractor company in India, under which the contractor undertakes the complete design and construction of a building for a fixed rate per square foot of built-up area — preparing all plans and drawings, obtaining approvals, and supplying all materials, labour and fittings. It covers the all-inclusive scope of the contract amount, commencement and completion with liquidated damages for delay, extensions and force majeure, variations, quality and inspection, statutory compliance, insurance and indemnity, defects liability and retention, completion and handing over, payment, termination, and dispute resolution by arbitration under Indian law.

A cost-plus building construction contract under which a contractor constructs a building on the owner's plot according to an architect's sanctioned plans, in India, for the actual cost of the works plus an agreed percentage as profit. It covers the required standard and manner of construction, the completion date and daily liquidated damages for delay, the architect's powers (to extend time, take over the works on the contractor's default, remove incompetent workmen or unfit materials, order rectification, and direct additions or alterations), the contractor's liability for damage and for legal compliance, restrictions on sub-contracting and assignment, the remuneration and monthly payment schedule, and the architect's final say on certification and release of payment.

This template is a construction agreement for situations where the **landowner provides the plot and all building materials**, while the contractor provides labour and tools. It includes clauses for completion timelines, liquidated damages for delays, quality inspections, and dispute resolution through arbitration.

An agreement appointing an architect firm to design and supervise the construction of a building for an owner (the Employer) in India. It sets out the architect's full scope of services — sketch designs, municipal approvals, working and structural drawings, estimates and tender documents, site supervision, checking contractors' bills and certifying payments, and obtaining the completion and occupation certificates — together with the standard of care and responsibility for structural soundness, submission timelines, the fee (a percentage of the value of works) and its stage-wise payment schedule, liquidated damages for delay, assignment and termination rights, and dispute resolution by arbitration under Indian law.

Line of Junction Notice for building a new wall wholly on own land under the Party Wall etc Act 1996