Free Contract law Templates

This template is a formal legal petition used in India to initiate a civil suit for the recovery of unpaid debts or outstanding balances. It includes sections for detailing the business relationship, invoices issued, payment defaults, and the calculation of interest, along with the necessary court verification and prayer for a decree.

An agreement under which the owner of machinery lets it out on hire to a hirer in India, for a fixed term at a monthly rent. It covers the rent and payment dates, restrictions on dealing with or removing the machinery, the hirer's duties to maintain and insure it (in the owner's name), application of insurance proceeds on loss, termination by notice or on default with the owner's right to repossess, the hirer's liability for licence fees and taxes, and dispute resolution by arbitration.

A turnkey building construction agreement between an owner (the Employer) and a contractor company in India, under which the contractor undertakes the complete design and construction of a building for a fixed rate per square foot of built-up area — preparing all plans and drawings, obtaining approvals, and supplying all materials, labour and fittings. It covers the all-inclusive scope of the contract amount, commencement and completion with liquidated damages for delay, extensions and force majeure, variations, quality and inspection, statutory compliance, insurance and indemnity, defects liability and retention, completion and handing over, payment, termination, and dispute resolution by arbitration under Indian law.

A cost-plus building construction contract under which a contractor constructs a building on the owner's plot according to an architect's sanctioned plans, in India, for the actual cost of the works plus an agreed percentage as profit. It covers the required standard and manner of construction, the completion date and daily liquidated damages for delay, the architect's powers (to extend time, take over the works on the contractor's default, remove incompetent workmen or unfit materials, order rectification, and direct additions or alterations), the contractor's liability for damage and for legal compliance, restrictions on sub-contracting and assignment, the remuneration and monthly payment schedule, and the architect's final say on certification and release of payment.

This template is a construction agreement for situations where the **landowner provides the plot and all building materials**, while the contractor provides labour and tools. It includes clauses for completion timelines, liquidated damages for delays, quality inspections, and dispute resolution through arbitration.

An agreement between a property owner and a broker in India, appointing the broker to sell the owner's house. It sets out the sale consideration and payment structure (earnest money followed by the balance at registration), the owner's warranties as to clear and marketable title, the owner's undertakings to deliver the title abstract and to execute the conveyance deed on receipt of the full consideration, the broker's timeline to find a buyer, and the broker's commission (2% of the consideration, payable on execution of the conveyance deed).

This template establishes a legal agreement for appointing an independent sales agent to promote and sell a company's computer hardware and software. It outlines the agent's responsibilities, tiered commission structure, territorial exclusivity, and detailed requirements for after-sales service and market reporting.

A short tripartite agreement by which a newly-incorporated company formally adopts and ratifies a contract that was entered into on its behalf before it was incorporated, in India. The company assumes the rights and obligations under the earlier contract as if it had existed at the date of that contract, and the promoter who signed on the company's behalf is discharged from all liability. It is executed under the company's common seal pursuant to a board resolution.

This document is a straightforward template for granting a license to use copyrighted material. It outlines the transfer of rights from the owner to a licensee for a specific purpose and duration in exchange for a payment.

This template is a formal agreement between a construction firm and a broker to facilitate the sale of a specific property. It outlines the broker's authority to find a buyer, sets the sale price and commission rate, and defines the timeline for the transaction.